Constitutes the third edition (1998) of the ACA's form of building agreement 1982 (2003 revision). Covers: contractor's general obligations; drawings, details, documents and information; obligations in respect of drawings, details, documents and information; visits to the works by the architect; supervision of the works by the contractor; vesting of property, contractor's indemnity and insurance; employer's liability; architect's instructions; assignment and sub-letting; employer's licensees; commencement and delays in the execution of the works; taking-over and defective work; taking-over of part of the works; antiquities; the contract sum; payment; valuation of architect's instructions; fluctuations; payment of the final contract sum; termination; termination due to causes outside the control of both parties; consequences of termination; notices and interpretation; construction industry scheme; disputes - conciliation, adjudication, litigation and arbitration; CDM Regulations; the time schedule; and stage payment schedule.
The ACA Model Conciliation Agreement is referred to in this agreement (it is bound into the 2003 revisions).
Founded in 1973, the Association of Consultant Architects represents architects in private practice throughout the UK. They are well known for their contracts and agreement documents.
NBS has produced specification systems and information products for construction industry professionals for more than 40 years. The National Building Specification is the recognised UK national standard and is used by over 5,000 organisations. NBS is part of RIBA Enterprises Ltd.
IHS Markit is a leading global source of critical information and insight for customers in a broad range of industries. Our customer product and service solutions span four major areas of information: energy, product lifecycle management, environmental and security. By focusing on our customers first, we deliver data and expertise that enable innovative and successful decision-making. Customers range from governments and multinational companies to smaller companies and technical professionals in more than 180 countries. IHS has been in business since 1959 and employs more than 3,500 people in 35 locations around the world.